W00000000 CITY OF PORT ST. JOE RFP 2022-16 PROJECT #50146260 AVE. C, D, and WILLIAMS AVE. PARKING RESURFACING NOTICE TO RECEIVE SEALED BIDS The City of Port St. Joe will receive …

Posted

W00000000

CITY OF PORT ST. JOE

RFP 2022-16

PROJECT #50146260

AVE. C, D, and WILLIAMS AVE. PARKING RESURFACING

NOTICE TO RECEIVE SEALED BIDS

The City of Port St. Joe will receive sealed bids from any qualified person, company or corporation interested in constructing:

AVE. C, D, and WILLIAMS AVE. PARKING RESURFACING

This project consists of milling and resurfacing approximately 0.29 miles of Avenue C & D from Martin Luther King Blvd. to Peters Street, along with paving Williams Avenue parking in Port St. Joe, Florida.

Plans and Specifications can be obtained by contacting Sharon Harrell at sharrell@dewberry.com with Dewberry Engineers Inc., 324 Marina Drive, Port St. Joe, Florida 32456, (850) 227-7200. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. There is no charge for electronic copies for the Plans and Specifications.

The completion date for this project will be 90 days for Substantial Completion and 120 days for Final Completion from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day.

Please indicate on the envelope that this is a sealed bid, for the "AVE. C, D, and WILLIAMS AVE. PARKING RESURFACING".

Bids will be received until 3:00 P.M., Eastern Time, on October 28, 2022, at the City of Port St. Joe City Hall, 305 Cecil G. Costin Sr. Blvd, Port St. Joe, Florida 32456, and will be opened and read aloud at 3:05 P.M., Eastern Time. The City of Port St. Joe is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.

The City of Port St. Joe reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in their best interest. All bids shall remain firm for a period of sixty days after the opening.

Questions regarding the project must be submitted in writing by,to Josh Stephens at jstephens@dewberry.com prior to October 14, 2022.

All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.

If you have any questions, please contact Josh Stephens at (850) 571-1218 or e-mail at jstephens@dewberry.com.

Publication Dates

Comments

No comments on this item Please log in to comment by clicking here